Terms & Conditions
Please read these terms carefully before engaging with our real estate developments, project consults, and construction services.
1. Welcome & Introduction
The Structural Engineers Ltd
Executive Summary
"Welcome to The Structural Engineers Ltd (SEL). Please read these terms carefully before engaging with our real estate listings, consultations, and construction services."
These terms and conditions outline the rules, regulations, and guidelines for the use of SEL's real estate developments, property consultation services, official corporate website, and related digital portals.
By accessing our properties, interacting with our customer relations team, or utilizing our website, you accept these terms in full. If you disagree with any part of these terms, please discontinue use of our site and services immediately.
Key Terms & Requirements
- Applies to all potential buyers, existing clients, and digital visitors of SEL.
- Forms a binding framework for all preliminary inquiries and property exploration.
- Effective as of June 2026.
2. Property Listings & Accuracy
The Structural Engineers Ltd
Executive Summary
"All residential, commercial, ongoing, and ready projects listed on our platform are subject to real-time availability, price adjustments, and verification."
The architectural drawings, specifications, floor plans, and amenities shown in our brochures or website represent design intent and are subject to regulatory approvals and availability.
While SEL takes maximum care to ensure all details and measurements are accurate, final constructed layouts may vary slightly due to structural configurations. Prices, down payment requirements, and installment schedules are subject to change without prior notice.
Key Terms & Requirements
- Subject to Availability: Unit allocations are locked only upon receipt of booking money.
- Independent Verification: Buyers are encouraged to inspect structural plans and layouts at the SEL Centre.
- No Liability for Layout Variations: Reasonable adjustments made for structural integrity are standard.
3. Service Agreement & Obligations
The Structural Engineers Ltd
Executive Summary
"We facilitate transparent property showings, valuation advice, and transaction documentation, while expecting clear cooperation from clients."
SEL provides end-to-end guidance for luxury apartment viewings, property valuation, legal documentation processing (including deed of agreement registration), and home loan assistance.
Clients are obligated to provide complete and accurate personal details during bookings and respond to official payment notifications within the agreed timelines.
Key Terms & Requirements
- Brokerage & Customizations: Unit modifications are subject to engineering design reviews.
- Client Response Time: Delays in responding to documentation requests may affect registration schedules.
- Verification: All legal paperwork must undergo formal processing at the SEL headquarters.
4. Payment Terms & Installments
The Structural Engineers Ltd
Executive Summary
"Our financial model is built on structured installments and milestone-based payments standard in Bangladesh's real estate sector."
All apartment, commercial space, or car parking bookings require booking money followed by down payment as specified in the property booking allocation form.
The remaining amount must be cleared in equal monthly installments or according to the construction milestones agreed upon in the Deed of Agreement. Late payments are subject to standard delayed interest fees.
Key Terms & Requirements
- Milestone Tracking: Installments tied directly to progress (e.g. foundation, roof casting, finishing).
- Late Fee Structure: Calculated at prevailing standard commercial bank lending rates.
- All payments must be made via Account Payee Cheque, Pay Order, or direct Bank Transfer to SEL accounts.
5. Cancellation & Refund Policies
The Structural Engineers Ltd
Executive Summary
"Booking cancellations and refunds are processed strictly in compliance with REHAB guidelines and the mutual Deed of Agreement."
If a client wishes to cancel an allotment booking prior to the execution of the deed, a formal written request must be submitted to the SEL management.
Refunds are processed after deducting a standard administrative and booking fee, and the disbursement timeline is subject to the re-allotment of the canceled unit to another buyer.
Key Terms & Requirements
- Cancellation Request Period: Standard written notice is required.
- Deduction Fee: Standard percentage or fixed booking money deduction for administration.
- Disbursement: Refund timeline is aligned with real estate industry standards in Bangladesh.
6. Limitation of Liability
The Structural Engineers Ltd
Executive Summary
"SEL holds no liability for force majeure delays or indirect consequential losses, urging clients to seek independent counsel where required."
We shall not be held liable for construction or handover delays caused by circumstances beyond our control, including force majeure events, natural disasters, sudden national materials price hikes, or delayed government utility connections.
All clients are advised to conduct their own personal due diligence and consult legal/financial advisors prior to completing final real estate purchase deeds.
Key Terms & Requirements
- Force Majeure: Covers acts of God, governmental policy changes, or political disruptions.
- No Indirect Damages: Liability is strictly limited to the actual terms of the signed property agreement.
7. Contact Information & Support
The Structural Engineers Ltd
Executive Summary
"Our customer care team and legal officers are available at the SEL Centre to assist you with any inquiries regarding these terms."
For further clarifications, legal documentation requests, or direct disputes regarding the terms of service, please visit our head office or reach out using the official contact details below.
We strive to resolve all buyer and visitor grievances through peaceful, direct bilateral negotiations before seeking legal arbitration.
Key Terms & Requirements
- Corporate Address: SEL Centre, 29 West Panthapath, Dhaka 1205, Bangladesh.
- Customer Care Hotline: 09666-773344
- Official Communication Mail: info@sel.com.bd